Fine Design Fabrication LIABILITY RELEASE AGREEMENT
Buyer agrees and does hereby release from all liability and hold harmless Fine Design Fabrication and any of its employees representing or related to Fine Design Fabrication. This liability release is for any and all liability for personal injuries including death and property losses or damage in connection with any product fabricated by or accommodation of the above mentioned Business.
By purchasing any product from our online store you agree that you have read and understand all details of this agreement and that all of the details listed in our terms & conditions are correct.
All sales and fabrication are final. An order that has been processed may not be cancelled. Once Fine Design Fabrication starts work on any project, the customer must agree to pay due amount upon completion. All Fine Design Fabrication products are paid in full upfront. Fine Design Fabrication will not release product or products until payment has been made in full.
DISPUTES (court action)
Any discrepancies or disputes that may end up in legal litigation of the court of law must be held in VENTURA COUNTY CALIFORNIA. By purchasing from Fine Design Fabrication, you agree to appear should you be requested or subpoenaed.
DELAYS
Seller shall have no liability to Buyer for any delays or damage to Seller’s performance caused by events beyond its control, including but not limited to strikes, acts of nature, civil disorders, fires, floods, adverse weather conditions, labor difficulties, delays in transportation, shortages of materials, delays in approval, change orders or submittals, and equipment failure/malfunctions.
INSTALLATION/ HANDLING
All of our products need to be handled very carefully throughout the entire process of unpackaging and installation. Materials such as copper, brass, zinc, and stainless all have very delicate finishes. These finishes can scratch very easily if mishandled during the unpackaging and installation process.
We take great care in our fabrication and packaging methods with quality control checks in every step of the production process. Detailed pictures and videos are taken of each finished product before it is shipped to ensure quality. Customer will be responsible for any shipping related fees and repair fees for damaged parts caused by mishandling.